Welcome to Centripetal Projects Private Limited (CPPL). By accessing or using our website and services, you agree to be bound by the following terms and conditions. Please read these terms carefully before using our services.

1. Introduction

These Terms and Conditions ("Agreement") govern your use of the website and the services provided by Centripetal Projects Private Limited (CPPL), a company specializing in electrical infrastructure projects, including substation construction, electrical contracting, and related services. By using our website or engaging with our services, you agree to comply with these terms.

2. Services Provided

CPPL offers the following services:

• Electrical Contracting Services including substation construction, transmission & distribution solutions, industrial & commercial electrification, HT/LT electrical works, and solar power solutions.
• Testing & Commissioning Services for electrical systems and equipment.
• Operations and Maintenance services for substations, transmission networks, and electrical utilities.
• Franchisee Distribution Networks (FDN) and customer grievance redressal systems.

Our services are detailed on our website. By engaging with us, you agree to the terms outlined for each service.

3. Use of the Website

By accessing the CPPL website, you agree:

• Not to use the site for any unlawful or unauthorized purpose.
• To provide accurate and up-to-date information when prompted (e.g., when making inquiries or submitting contact details).
• Not to interfere with or disrupt the website’s functionality or security features.
• Not to use the website for spamming, phishing, or any harmful activities.

CPPL reserves the right to block or terminate access to the website for users who violate these terms.

4. Client Responsibilities

As a client of CPPL, you agree to:

• Provide accurate and timely information regarding project specifications, site conditions, and other project-related requirements.
• Ensure that CPPL's personnel have access to the necessary site locations and information for successful project execution.
• Pay for the services rendered as per the agreed terms, including any applicable taxes and fees.

5. Payment Terms

Payment for services rendered shall be made according to a schedule mutually agreed upon by both the Client and the Contractor prior to the commencement of work. This may include an initial deposit, progress payments based on project milestones, and a final payment upon completion. All terms shall be outlined in writing and signed by both parties. Any changes to the payment schedule must be agreed upon in writing.

6. Confidentiality and Privacy

CPPL respects your privacy and ensures that all personal and project-related information provided to us is confidential. We will not disclose any confidential information to third parties without your consent, except as required by law.

• We collect and use personal data in accordance with our Privacy Policy.
• CPPL will implement appropriate technical and organizational measures to protect your information from unauthorized access or disclosure.

7. Intellectual Property

All content on the CPPL website, including logos, graphics, text, images, and design elements, are the intellectual property of CPPL or third-party licensors and are protected by copyright laws. You may not copy, reproduce, or use any content without express permission.

8. Limitation of Liability

CPPL will not be liable for any direct, indirect, incidental, special, or consequential damages arising from:

• The use or inability to use our website or services.
• Any loss or damage to your property, including systems and data, resulting from using CPPL services.
• Any delay, errors, or omissions in delivering our services as a result of unforeseen circumstances or events beyond our control.

We recommend that you maintain backup systems and data throughout the project duration.

9. Force Majeure

CPPL will not be held liable for any failure or delay in service delivery due to force majeure events, including natural disasters, war, strikes, government actions, or any other event beyond the reasonable control of CPPL.

10. Amendments to Terms and Conditions

CPPL reserves the right to update or modify these terms and conditions at any time. All changes will be posted on this page with an updated revision date. Your continued use of our services or website after any changes indicates your acceptance of the modified terms.

11. Termination of Services

CPPL reserves the right to terminate or suspend services if:

• The client fails to meet payment obligations.
• There is a breach of the terms and conditions.
• Services are no longer needed or requested by the client.

CPPL may terminate any agreement with immediate effect if there are any violations of these terms.

12. Dispute Resolution

In the event of a dispute, we will attempt to resolve the issue through informal negotiations. If the dispute cannot be resolved informally, it will be handled through arbitration in accordance with Indian Arbitration Law. The location for arbitration will be [Insert City], and the decision of the arbitrator will be binding.

13. Governing Law

These Terms and Conditions are governed by the laws of India. Any legal action or proceeding related to these terms shall be exclusively brought in the competent courts located in [Insert City], India.

14. Contact Information

For any questions regarding these terms or our services, please contact us at:

Centripetal Projects Private Limited (CPPL)
Email: centripetalprojects@gmail.com, enquiry@centripetalprojects.com
Phone: +91-9838707479
Address: PLOT NO. 26, K.NO. 1133, KOTRA, AJMER - 305001